Terms of Service
Last Updated: June 2026
Welcome to Mardaya
Welcome to Mardaya ("Mardaya," "Company," "we," "our," or "us").
Our mission is simple:
To provide dependable construction, property preservation, maintenance, repair, renovation, and project management services with integrity, professionalism, quality craftsmanship, and clear communication.
These Terms of Service govern your use of MardayaCorp.com, our services, communications, estimates, project consultations, and all interactions with Mardaya.
By accessing our website, submitting information, requesting services, scheduling consultations, accepting estimates, or engaging our services, you agree to these Terms of Service.
If you do not agree to these Terms, please do not use our website or services.
1. Eligibility
You must be at least 18 years old and legally capable of entering into binding agreements to use our website or engage our services.
If you are acting on behalf of a business, organization, property owner, investor, or management company, you represent that you have authority to bind that entity.
2. Services Provided
Mardaya may provide services including but not limited to:
Property preservation
Residential construction
Commercial construction
Remodeling and renovations
Repairs and maintenance
Property inspections
Site clean-up
Project management
Consulting services
Contractor coordination
Emergency service work
Other related construction and property services
Service availability may vary by location, project scope, scheduling requirements, weather conditions, subcontractor availability, and material availability.
3. Estimates and Proposals
Any estimate, proposal, quote, or bid provided by Mardaya is based upon information available at the time of inspection or review.
Unless otherwise stated in writing:
Estimates are valid for 30 days.
Pricing may change due to material costs, labor costs, site conditions, code requirements, or requested modifications.
Additional work requested after project commencement may require written approval and additional charges.
No project shall begin until both parties have agreed upon the scope of work.
4. Payment Terms
Payment terms will be outlined in project proposals, invoices, contracts, or service agreements.
Unless otherwise stated:
Deposits may be required before work begins.
Progress payments may be required during larger projects.
Final payment is due upon project completion.
Late payments may incur reasonable collection costs and applicable interest permitted by law.
Failure to make timely payments may result in suspension of work until accounts are brought current.
5. Project Delays
Project schedules are estimates only.
Mardaya shall not be responsible for delays caused by:
Weather conditions
Material shortages
Supply chain disruptions
Permit delays
Utility interruptions
Labor shortages
Government actions
Client-requested changes
Circumstances beyond our reasonable control
Completion dates are not guaranteed unless specifically stated in writing.
6. Customer Responsibilities
Customers agree to:
Provide accurate project information
Provide reasonable access to project sites
Secure pets and personal belongings
Obtain approvals when required
Disclose known property conditions
Make payments according to agreed terms
Mardaya is not responsible for delays or damages resulting from inaccurate or incomplete information provided by customers.
7. Website Use
You agree not to:
Use the website for unlawful purposes
Attempt unauthorized access to systems
Interfere with website functionality
Introduce malicious software
Copy, reproduce, or distribute website content without permission
Misrepresent your identity
We reserve the right to restrict access to users who violate these Terms.
8. Intellectual Property
All website content, logos, graphics, text, photographs, videos, designs, and branding are the property of Mardaya unless otherwise indicated.
No content may be copied, reproduced, modified, distributed, or used without prior written permission.
9. Marketing Communications
By voluntarily providing your contact information through our website, forms, service requests, or consultations, you consent to receive communications from Mardaya, including:
Appointment reminders
Project updates
Customer service communications
Promotional messages
SMS messages
Email communications
Message and data rates may apply.
Consent is not a condition of purchase.
You may opt out at any time by:
Replying STOP to SMS messages
Clicking unsubscribe in emails
Contacting us directly
10. Warranty Disclaimer
Except where required by law or expressly stated in writing, services and website content are provided "as is" and "as available."
Mardaya makes no guarantees regarding:
Specific project outcomes
Increased property value
Financial returns
Market performance
Future property conditions
Construction and property conditions vary by project and location.
11. Limitation of Liability
To the maximum extent permitted by law, Mardaya shall not be liable for:
Indirect damages
Incidental damages
Consequential damages
Lost profits
Lost business opportunities
Loss of use
Delays beyond our reasonable control
Our total liability arising from any claim shall not exceed the amount paid by the customer for the specific services giving rise to the claim.
12. Indemnification
You agree to defend, indemnify, and hold harmless Mardaya, its owners, employees, contractors, subcontractors, and affiliates from claims, damages, liabilities, expenses, and costs arising from:
Your misuse of our services
Violation of these Terms
Property conditions not disclosed to us
Actions taken by third parties under your direction
13. Dispute Resolution
Before initiating legal action, both parties agree to attempt good-faith resolution through direct communication.
If a dispute cannot be resolved informally, it shall be resolved under the laws of the State of Georgia, without regard to conflict of law principles.
Any legal proceeding shall be brought in a court of competent jurisdiction located within Georgia.
14. Force Majeure
Mardaya shall not be liable for delays or failures caused by events beyond reasonable control, including:
Natural disasters
Severe weather
Fire
Flood
Labor disputes
Government actions
Supply chain disruptions
Utility failures
Acts of God
15. Changes to These Terms
We reserve the right to update these Terms at any time.
Changes become effective upon posting to MardayaCorp.com.
Continued use of our website or services constitutes acceptance of updated Terms.
16. Severability
If any provision of these Terms is determined to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.
17. Entire Agreement
These Terms of Service, together with our Privacy Policy and any written project agreements, proposals, estimates, or contracts, constitute the entire agreement between the parties.
18. Contact Information
Mardaya
Website: MardayaCorp.com
Email: [email protected]
Phone: (404) 671-8366
SMS Communication Notice
By providing your phone number through our website, service forms, consultation requests, or project communications, you agree to receive calls and text messages from Mardaya regarding appointments, estimates, projects, customer support, and marketing communications.
Message and data rates may apply.
You may opt out at any time by replying STOP to any text message or by contacting us directly at [email protected] or (404) 671-8366.